Last Updated: 2026

Welcome to Design Hunt Interiors. By accessing or using our website https://designhuntinteriors.com/, you agree to comply with and be bound by the following Terms and Conditions. Please read these terms carefully before using our website or services.

EL ARTE DESIGN HUNT PRIVATE LIMITED, operating under the brand name Design Hunt Interiors (“we”, “our”, or “us”), respects your privacy and is committed to protecting your personal information.

If you do not agree with these terms, please refrain from using our website.

1. Introduction

Design Hunt Interiors provides interior design services, modular interior solutions, furniture design, and turnkey interior fit-out services for residential and commercial spaces.

These Terms & Conditions govern your use of our website and the services offered through it.

2. Use of Website

By using this website, you agree to:

Use the website only for lawful purposes.
Not misuse or attempt to gain unauthorized access to any part of the website.
Not use the website for fraudulent activities.
Provide accurate and complete information when submitting forms or inquiries.

We reserve the right to restrict or terminate access to users who violate these terms.

3. Services Provided

Design Hunt Interiors provides services including but not limited to:

Interior Design Consultation
Modular Kitchen & Wardrobe Design
Furniture & Furnishing Solutions
Residential & Commercial Interior Fit-outs
Turnkey Interior Design Projects

All services are subject to project agreements, quotations, and mutually agreed terms between the client and Design Hunt Interiors.

4. Quotations & Pricing

All quotations provided by Design Hunt Interiors are valid only for the specified time mentioned in the quotation.
Prices may vary depending on project scope, materials, customization, and site conditions.
Any changes requested by the client during project execution may affect the project cost and timeline.

5. Payments

Payment terms will be defined in the project agreement or quotation. Typically:

An advance payment is required before project initiation.
Payment milestones may be defined based on project stages.
Final payment must be completed before project handover.

Failure to complete payments may lead to project suspension or delay.

6. Project Timelines

Design Hunt Interiors strives to complete projects within the agreed timeline. However, delays may occur due to:

Site readiness issues
Client approval delays
Material availability
Force majeure events

Such delays will be communicated to the client whenever possible.

7. Intellectual Property

All content on this website including:

Designs
Images
Graphics
Text
Logos
Layouts

are the property of Design Hunt Interiors and may not be copied, reproduced, or used without prior written permission.

8. Third-Party Links

Our website may contain links to third-party websites. These links are provided for convenience only.

Design Hunt Interiors is not responsible for the content, policies, or practices of third-party websites.

9. Limitation of Liability

Design Hunt Interiors shall not be liable for:

Any indirect or consequential damages
Losses resulting from website use
Delays caused by external factors beyond our control

Users access and use the website at their own risk.

10. Warranty

Any warranty for materials, fittings, or products used in interior projects will depend on the manufacturer’s warranty policies and the specific project agreement.

11. Privacy

Any personal information submitted through forms on this website will be handled in accordance with our Privacy Policy.

12. Changes to Terms

Design Hunt Interiors reserves the right to modify or update these Terms & Conditions at any time without prior notice.

Users are encouraged to review this page periodically.

13. Governing Law

These Terms & Conditions shall be governed by and interpreted in accordance with the laws of India.

Any disputes arising from these terms shall fall under the jurisdiction of the courts located in Chennai, Tamil Nadu.

14. Need help?

If you have any questions regarding these Terms & Conditions, please contact us:

Design Hunt Interiors
Website: https://designhuntinteriors.com/
Email: info@designhuntinteriors.com
Location: Chennai, Tamil Nadu, India